Loading...
Serving La Quinta, CA and surrounding areas. (442) 446-1461
Effective date: January 1, 2026. Last updated: January 1, 2026.
By using the website located at laquintafence.com or by hiring Total La Quinta Fence to perform any fence-related service, you agree to these Terms and Conditions. If you do not agree, please do not use this website or engage our services.
These terms apply to all visitors, customers, and anyone else who interacts with our website or our team.
Total La Quinta Fence is a fence contractor serving residential and commercial customers in La Quinta, CA and surrounding Coachella Valley communities. Our services include fence installation, repair, replacement, custom design, gate installation, and related work.
All services are provided by or under the supervision of licensed professionals. We reserve the right to decline any project that falls outside our service area, scope of expertise, or schedule availability.
Written estimates provided by Total La Quinta Fence are based on the information available at the time of the site visit. Estimates are valid for 30 days from the date they are issued unless otherwise noted in writing.
The final invoice may differ from the original estimate if the scope of work changes, if unforeseen conditions are discovered during the project (such as buried obstacles, soil conditions, or permit requirements not identified during the estimate), or if the customer requests additional work. We will communicate any material changes to the price before proceeding.
Verbal quotes are not binding. Only written estimates signed by both parties constitute a project agreement.
Project dates are scheduled based on crew availability, permit timelines, and material lead times. We will communicate the expected start date in writing before work begins.
If you need to cancel or postpone a scheduled project, please notify us as soon as possible. Cancellations made fewer than 48 hours before the scheduled start date may be subject to a rescheduling fee to cover crew scheduling costs. Any deposits paid are refundable if the project is cancelled before materials are ordered.
We reserve the right to postpone or reschedule work due to weather conditions, crew illness, permit delays, or other circumstances outside our control. In such cases, we will notify you promptly and reschedule at the earliest available time.
Payment terms are outlined in your written project agreement. In general, a deposit may be required before materials are ordered. The remaining balance is due upon project completion unless other terms have been agreed upon in writing.
Late payments may be subject to a finance charge of 1.5 percent per month on the outstanding balance, or the maximum rate permitted by California law, whichever is lower. If collection action becomes necessary, the customer agrees to pay all reasonable collection costs, including attorney fees.
We accept payment by check, cash, and credit card. A processing fee may apply to credit card payments - this will be disclosed at the time of invoicing.
Before work begins, the customer is responsible for:
Total La Quinta Fence is not responsible for damage to unmarked underground utilities or for work that does not comply with HOA rules if the customer did not disclose those rules before the project began.
We stand behind our work. Our labor warranty covers defects in workmanship for one year from the project completion date. If a defect in our installation is identified within that period, we will return to correct it at no charge.
Materials are covered by the manufacturer's warranty, which varies by product. We will provide manufacturer warranty documentation upon request. Warranty claims related to materials must be submitted through the manufacturer's process - we will assist where we can, but cannot extend coverage beyond what the manufacturer provides.
This warranty does not cover damage caused by accidents, misuse, extreme weather events, vandalism, improper maintenance, or modifications made by anyone other than Total La Quinta Fence.
To the fullest extent permitted by California law, the total liability of Total La Quinta Fence for any claim arising from our services or this website is limited to the amount you paid us for the specific project or service giving rise to the claim.
We are not liable for indirect, incidental, consequential, or punitive damages of any kind, including lost profits, loss of use, or damage to property not directly caused by our work. This limitation applies regardless of the theory of liability (contract, tort, or otherwise).
Information provided on this website is for general purposes only and does not constitute professional advice for your specific property or situation. We make no warranty that the website will be uninterrupted, error-free, or free of viruses or other harmful components.
The website and all content on it are provided "as is" without warranties of any kind, express or implied, including but not limited to implied warranties of merchantability, fitness for a particular purpose, or non-infringement.
If a dispute arises between you and Total La Quinta Fence related to our services or these terms, both parties agree to first attempt to resolve it informally by contacting us at team@laquintafence.com. We will make a good-faith effort to respond and work toward a resolution within 10 business days.
If informal resolution is not possible, any dispute will be submitted to binding arbitration in La Quinta, California, under the rules of the American Arbitration Association. The arbitrator's decision will be final and may be entered as a judgment in any court of competent jurisdiction.
You waive any right to a jury trial or to participate in a class action lawsuit against Total La Quinta Fence.
These Terms and Conditions are governed by the laws of the State of California, without regard to its conflict of law provisions. Any legal action not subject to arbitration will be brought exclusively in the courts of Riverside County, California.
We may update these Terms and Conditions at any time. When we do, we will update the effective date at the top of this page. Your continued use of our website or services after any changes means you accept the updated terms. We encourage you to review this page periodically.
Questions about these terms? Reach us at: